[DOWNLOAD] "Ernest C. Siefford and John C. Beall v." by Supreme Court of Nebraska # eBook PDF Kindle ePub Free
eBook details
- Title: Ernest C. Siefford and John C. Beall v.
- Author : Supreme Court of Nebraska
- Release Date : January 05, 1974
- Genre: Law,Books,Professional & Technical,
- Pages : * pages
- Size : 70 KB
Description
This case involves a contract for the construction of a housing project at Humboldt, Nebraska, entered into between the appellant, Beall-Siefford Construction Company a joint venture consisting of John C. Beall and Ernest C. Siefford, hereinafter referred to as Contractor, and the appellee, Housing Authority of the City of Humboldt, Nebraska, hereinafter referred to as Housing Authority. The Housing Authority opened bids for the project on July 14, 1964. The Contractor's bid of $330,288 was low and was approved on August 17, 1964. Notice to proceed on September 8, 1964, was given the Contractor. According to the construction contract between the parties, the Contractor was to complete the dwelling units in 365 calendar days or by September 7, 1965, and the community building 65 days earlier. However, the project was not fully completed and accepted until January 5, 1966, meaning that there was an overrun of time of 162 days for the community building, and 119 days for the dwelling units. In its amended petition filed on July 10, 1972, the Contractor sets out three causes of action, or, to be more precise, three theories of recovery, against the Housing Authority. The first cause of action is based on the theory of money due under the contract. It alleges the contract price and extras in the amount of $339,462.16, and that Housing Authority has paid $335,832.16 and still owes $3,630, being the amount of liquidated damages witheld by the Housing Authority for delay of the Contractor in performing the contract, and also claims an additional $70,630.21 for additional labor and material plus $2,009.05 for changes in the contract with respect to maintaining the lawns. In its second cause of action, based on the theory of quantum meruit, Contractor claims the sum of $72,639.26 for additional labor and materials, in addition to the $3,630 previously referred to as due under the written contract. Contractor's third cause of action was a claim of damages for breach of contract based on the theory of acceleration as hereinafter discussed. The amount of these damages is again alleged to be $72,639.26, which is claimed in addition to the $3,630 remaining under the original contract. The Housing Authority filed the appropriate responsive pleadings and the pretrial hearing was held upon the matter on June 8, 1973, at which time the issues were limited for purposes of trial and confined to six items, to-wit: